Repair B300 Hot Water Heaters FA6670-26-B-0001

This is a Advanced Solicitation Notice. This notice does NOT constitute a request for proposal, request for quote or invitation for bid. Estimated issue date for the solicitation is on or after 13 March 2026, with the solicitation closing approximately 30 days thereafter. It will be issued electronically at the Sam website https://sam.gov under the reference number FA6670-26-B-0001. Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair Hot Water Heaters B300. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 25-0008, Repair Hot Water Heaters B300, to include the following: This project will repair the hot water (HW) heater tank for B300 by replacement. Demolish and dispose of existing HW tank. Provide valves, piping, venting, insulation, and electrical components as necessary to facilitate a complete and proper installation. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 45 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.106. The NAICS code is 238220 and the Small Business Size Standard is $19,000,000. Electronic bid submissions will not be accepted or returned. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.

A Site Vist has been scheduled for- Thursday March 19, 2026 at 2:00 pm Meet at- 2720 Kirkbridge Dr, Bldg. 800, Rm 1027, Niagara Falls, NY 14304 Instructions to obtain base access can be found in Section L. Attachment 4 MUST be e-mailed to Contracting Office by 2 pm on Wednesday 18 March 2026. **PER FEDERAL GUIDELINES as of May 7, 2025, ALL personnel requesting access to the Niagara Falls Air Reserve Station must have one of the following to be allowed entry: Valid State Enhanced or Real ID, or Valid United States Passport** Prime contractors, subcontractors and/or suppliers may attend the site visit. _______________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair Hot Water Heaters B300. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 25-0008, Repair Hot Water Heaters B300, to include the following: This project will repair the hot water (HW) heater tank for B300 by replacement. Demolish and dispose of existing HW tank. Provide valves, piping, venting, insulation, and electrical components as necessary to facilitate a complete and proper installation. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 45 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.106. The NAICS code is 238220 and the Small Business Size Standard is $19,000,000. Electronic bid submissions will not be accepted or returned. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.

Questions are due via e-mail NLT COB 24 March 2026. Answers will be posted approx 3 to 5 days after. _____________________________________________________________ A Site Visit has been scheduled for- Thursday March 19, 2026 at 2:00 pm Meet at- 2720 Kirkbridge Dr, Bldg. 800, Rm 1027, Niagara Falls, NY 14304 Instructions to obtain base access can be found in Section L. Attachment 4 MUST be e-mailed to Contracting Office by 2 pm on Wednesday 18 March 2026. **PER FEDERAL GUIDELINES as of May 7, 2025, ALL personnel requesting access to the Niagara Falls Air Reserve Station must have one of the following to be allowed entry: Valid State Enhanced or Real ID, or Valid United States Passport** Prime contractors, subcontractors and/or suppliers may attend the site visit. _______________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair Hot Water Heaters B300. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 25-0008, Repair Hot Water Heaters B300, to include the following: This project will repair the hot water (HW) heater tank for B300 by replacement. Demolish and dispose of existing HW tank. Provide valves, piping, venting, insulation, and electrical components as necessary to facilitate a complete and proper installation. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 45 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.106. The NAICS code is 238220 and the Small Business Size Standard is $19,000,000. Electronic bid submissions will not be accepted or returned. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.

26 March 2026 Amendment 1 issued to incorporate attachments 5, 6, 7, 8 and 9. _____________________________________________________________ Questions are due via e-mail NLT COB 24 March 2026. Answers will be posted approx 3 to 5 days after. _____________________________________________________________ A Site Visit has been scheduled for- Thursday March 19, 2026 at 2:00 pm Meet at- 2720 Kirkbridge Dr, Bldg. 800, Rm 1027, Niagara Falls, NY 14304 Instructions to obtain base access can be found in Section L. Attachment 4 MUST be e-mailed to Contracting Office by 2 pm on Wednesday 18 March 2026. **PER FEDERAL GUIDELINES as of May 7, 2025, ALL personnel requesting access to the Niagara Falls Air Reserve Station must have one of the following to be allowed entry: Valid State Enhanced or Real ID, or Valid United States Passport** Prime contractors, subcontractors and/or suppliers may attend the site visit. _______________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair Hot Water Heaters B300. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 25-0008, Repair Hot Water Heaters B300, to include the following: This project will repair the hot water (HW) heater tank for B300 by replacement. Demolish and dispose of existing HW tank. Provide valves, piping, venting, insulation, and electrical components as necessary to facilitate a complete and proper installation. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 45 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.106. The NAICS code is 238220 and the Small Business Size Standard is $19,000,000. Electronic bid submissions will not be accepted or returned. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.