12905B25R0002 Cancellation of Requirement for Water Well Repair USDA-ARS-PWA Dubois ID 12905B25R0002

Amendment 0001 - Corrects the response date listed on the SF 1442, Block 13. Change the response dated from 5/23/2025 to 6/30/2025. The United States Department of Agriculture (USDA), Agricultural Research Service (ARS), Pacific West Area Office has a construction requirement for repair of the water well to include drilling a new shaft at RSPERC 19 Office Loop Duboise ID 83423. The Contractor shall provide all labor, equipment, materials, supplies, transportation and supervision performing all required work in accordance with the plans and specifications for this requirement This is the only official location where these documents can be obtained and where updates are posted. This requirement is being solicited on an UNRESTRICTED basis. Potential Offerors are responsible for monitoring this site for release of any amendments. No hard copy solicitation materials are available. No paper copies of the solicitation will be mailed, and telephone requests will not be honored. MAGNITUDE OF CONSTRUCTION PROJECT - Between $1,000,000.00 and $5,000.000.00 A single organized site visit is completed on Wednesday, 28 May, 2025 at TIME 11:00a.m. Mountain Time. No Questions will be entertained at the site visit. See below. Please ensure to sign on-site sign-in sheet All questions pertaining to this solicitation, including questions that arise during the site visit, must be submitted to theodore.blume@usda.gov by 10:00 a.m. Mountain Daylight Time, Thursday, 12 June 2025 via the Attachment VI - RFI form. Bid Bond Guarantees are also required when the proposal is above $150K. Proposals are to receive no later than 5:00 p.m. Mountain Time, Monday, 30 June 2025. Proposal must be in writing following Section L guidelines and emailed to: theodore.blume@usda.gov PROPOSAL MUST BE ANNOTATED AS SUCH AND REFERENCE THE SOLICITATION NUMBER. 12905B25R0002. Late proposals submitted after this deadline may be considered only if it is in the government s best interest and if it will not unduly delay award. Note: Performance and Payment bonds will be required after award should they meet the threshold per FAR 28.102. As a general reference, payment bonds are needed for all proposals above $35K and performance bonds are needed above $150K. Payment and Performance bonds are due ten (10) days after award and must be accepted by the Contracting Officer.

Amendment 00003 - The closing date for this requirement has been extended to 10/2/2025. See Attached Amendment 00003. Remember, all Amendments shall be signed and returned with your proposal or your proposal will be considered non-responsive. Amendment 00002 - Extends the close date to 7/16/2025. Amendment 00001 - Corrects the response date listed on the SF 1442, Block 13. Change the response dated from 5/23/2025 to 6/30/2025. The United States Department of Agriculture (USDA), Agricultural Research Service (ARS), Pacific West Area Office has a construction requirement for repair of the water well to include drilling a new shaft at RSPERC 19 Office Loop Duboise ID 83423. The Contractor shall provide all labor, equipment, materials, supplies, transportation and supervision performing all required work in accordance with the plans and specifications for this requirement This is the only official location where these documents can be obtained and where updates are posted. This requirement is being solicited on an UNRESTRICTED basis. Potential Offerors are responsible for monitoring this site for release of any amendments. No hard copy solicitation materials are available. No paper copies of the solicitation will be mailed, and telephone requests will not be honored. MAGNITUDE OF CONSTRUCTION PROJECT - Between $1,000,000.00 and $5,000.000.00 A single organized site visit is completed on Wednesday, 28 May, 2025 at TIME 11:00a.m. Mountain Time. No Questions will be entertained at the site visit. See below. Please ensure to sign on-site sign-in sheet All questions pertaining to this solicitation, including questions that arise during the site visit, must be submitted to theodore.blume@usda.gov by 10:00 a.m. Mountain Daylight Time, Thursday, 12 June 2025 via the Attachment VI - RFI form. Bid Bond Guarantees are also required when the proposal is above $150K. Proposals are to receive no later than 5:00 p.m. Mountain Time, Monday, 30 June 2025. Proposal must be in writing following Section L guidelines and emailed to: theodore.blume@usda.gov PROPOSAL MUST BE ANNOTATED AS SUCH AND REFERENCE THE SOLICITATION NUMBER. 12905B25R0002. Late proposals submitted after this deadline may be considered only if it is in the government s best interest and if it will not unduly delay award. Note: Performance and Payment bonds will be required after award should they meet the threshold per FAR 28.102. As a general reference, payment bonds are needed for all proposals above $35K and performance bonds are needed above $150K. Payment and Performance bonds are due ten (10) days after award and must be accepted by the Contracting Officer.

Amendment 00004 - The closing date of this requirement has been extended to 11/6/2025. See Attached Amendment 00004. Amendment 00003 - The closing date for this requirement has been extended to 10/2/2025. See Attached Amendment 00003. Remember, all Amendments shall be signed and returned with your proposal or your proposal will be considered non-responsive. Amendment 00002 - Extends the close date to 7/16/2025. Amendment 00001 - Corrects the response date listed on the SF 1442, Block 13. Change the response dated from 5/23/2025 to 6/30/2025. The United States Department of Agriculture (USDA), Agricultural Research Service (ARS), Pacific West Area Office has a construction requirement for repair of the water well to include drilling a new shaft at RSPERC 19 Office Loop Duboise ID 83423. The Contractor shall provide all labor, equipment, materials, supplies, transportation and supervision performing all required work in accordance with the plans and specifications for this requirement This is the only official location where these documents can be obtained and where updates are posted. This requirement is being solicited on an UNRESTRICTED basis. Potential Offerors are responsible for monitoring this site for release of any amendments. No hard copy solicitation materials are available. No paper copies of the solicitation will be mailed, and telephone requests will not be honored. MAGNITUDE OF CONSTRUCTION PROJECT - Between $1,000,000.00 and $5,000.000.00 A single organized site visit is completed on Wednesday, 28 May, 2025 at TIME 11:00a.m. Mountain Time. No Questions will be entertained at the site visit. See below. Please ensure to sign on-site sign-in sheet All questions pertaining to this solicitation, including questions that arise during the site visit, must be submitted to theodore.blume@usda.gov by 10:00 a.m. Mountain Daylight Time, Thursday, 12 June 2025 via the Attachment VI - RFI form. Bid Bond Guarantees are also required when the proposal is above $150K. Proposals are to receive no later than 5:00 p.m. Mountain Time, Monday, 30 June 2025. Proposal must be in writing following Section L guidelines and emailed to: theodore.blume@usda.gov PROPOSAL MUST BE ANNOTATED AS SUCH AND REFERENCE THE SOLICITATION NUMBER. 12905B25R0002. Late proposals submitted after this deadline may be considered only if it is in the government s best interest and if it will not unduly delay award. Note: Performance and Payment bonds will be required after award should they meet the threshold per FAR 28.102. As a general reference, payment bonds are needed for all proposals above $35K and performance bonds are needed above $150K. Payment and Performance bonds are due ten (10) days after award and must be accepted by the Contracting Officer.

Amendment 0005 - The closing date of this requirement has been extended to 1/30/2026. See Attached Amendment 0005. Amendment 00004 - The closing date of this requirement has been extended to 11/6/2025. See Attached Amendment 00004. Amendment 00003 - The closing date for this requirement has been extended to 10/2/2025. See Attached Amendment 00003. Remember, all Amendments shall be signed and returned with your proposal or your proposal will be considered non-responsive. Amendment 00002 - Extends the close date to 7/16/2025. Amendment 00001 - Corrects the response date listed on the SF 1442, Block 13. Change the response dated from 5/23/2025 to 6/30/2025. The United States Department of Agriculture (USDA), Agricultural Research Service (ARS), Pacific West Area Office has a construction requirement for repair of the water well to include drilling a new shaft at RSPERC 19 Office Loop Duboise ID 83423. The Contractor shall provide all labor, equipment, materials, supplies, transportation and supervision performing all required work in accordance with the plans and specifications for this requirement This is the only official location where these documents can be obtained and where updates are posted. This requirement is being solicited on an UNRESTRICTED basis. Potential Offerors are responsible for monitoring this site for release of any amendments. No hard copy solicitation materials are available. No paper copies of the solicitation will be mailed, and telephone requests will not be honored. MAGNITUDE OF CONSTRUCTION PROJECT - Between $1,000,000.00 and $5,000.000.00 A single organized site visit is completed on Wednesday, 28 May, 2025 at TIME 11:00a.m. Mountain Time. No Questions will be entertained at the site visit. See below. Please ensure to sign on-site sign-in sheet All questions pertaining to this solicitation, including questions that arise during the site visit, must be submitted to theodore.blume@usda.gov by 10:00 a.m. Mountain Daylight Time, Thursday, 12 June 2025 via the Attachment VI - RFI form. Bid Bond Guarantees are also required when the proposal is above $150K. Proposals are to receive no later than 5:00 p.m. Mountain Time, Monday, 30 June 2025. Proposal must be in writing following Section L guidelines and emailed to: theodore.blume@usda.gov PROPOSAL MUST BE ANNOTATED AS SUCH AND REFERENCE THE SOLICITATION NUMBER. 12905B25R0002. Late proposals submitted after this deadline may be considered only if it is in the government s best interest and if it will not unduly delay award. Note: Performance and Payment bonds will be required after award should they meet the threshold per FAR 28.102. As a general reference, payment bonds are needed for all proposals above $35K and performance bonds are needed above $150K. Payment and Performance bonds are due ten (10) days after award and must be accepted by the Contracting Officer.

Amendment 00006 - The closing date of this requirement has been extended to 3/16/2026. Additional documents will be uploaded under Amendment - 00006. This included DESCOPED SPECIFICATIONS AND DRAWINGS. RFI responses are uploaded here. . It is the contractor's responsivility to monitor this announcement for changes/uploaded documents. Amendment 0005 - The closing date of this requirement has been extended to 1/30/2026. See Attached Amendment 0005. Amendment 00004 - The closing date of this requirement has been extended to 11/6/2025. See Attached Amendment 00004. Amendment 00003 - The closing date for this requirement has been extended to 10/2/2025. See Attached Amendment 00003. Remember, all Amendments shall be signed and returned with your proposal or your proposal will be considered non-responsive. Amendment 00002 - Extends the close date to 7/16/2025. Amendment 00001 - Corrects the response date listed on the SF 1442, Block 13. Change the response dated from 5/23/2025 to 6/30/2025. The United States Department of Agriculture (USDA), Agricultural Research Service (ARS), Pacific West Area Office has a construction requirement for repair of the water well to include drilling a new shaft at RSPERC 19 Office Loop Duboise ID 83423. The Contractor shall provide all labor, equipment, materials, supplies, transportation and supervision performing all required work in accordance with the plans and specifications for this requirement This is the only official location where these documents can be obtained and where updates are posted. This requirement is being solicited on an UNRESTRICTED basis. Potential Offerors are responsible for monitoring this site for release of any amendments. No hard copy solicitation materials are available. No paper copies of the solicitation will be mailed, and telephone requests will not be honored. MAGNITUDE OF CONSTRUCTION PROJECT - Between $1,000,000.00 and $5,000.000.00 A single organized site visit is completed on Wednesday, 28 May, 2025 at TIME 11:00a.m. Mountain Time. No Questions will be entertained at the site visit. See below. Please ensure to sign on-site sign-in sheet All questions pertaining to this solicitation, including questions that arise during the site visit, must be submitted to theodore.blume@usda.gov by 10:00 a.m. Mountain Daylight Time, Thursday, 12 June 2025 via the Attachment VI - RFI form. Bid Bond Guarantees are also required when the proposal is above $150K. Proposals are to receive no later than 5:00 p.m. Mountain Time, Monday, 30 June 2025. Proposal must be in writing following Section L guidelines and emailed to: theodore.blume@usda.gov PROPOSAL MUST BE ANNOTATED AS SUCH AND REFERENCE THE SOLICITATION NUMBER. 12905B25R0002. Late proposals submitted after this deadline may be considered only if it is in the government s best interest and if it will not unduly delay award. Note: Performance and Payment bonds will be required after award should they meet the threshold per FAR 28.102. As a general reference, payment bonds are needed for all proposals above $35K and performance bonds are needed above $150K. Payment and Performance bonds are due ten (10) days after award and must be accepted by the Contracting Officer.

This notice is to CANCEL this requirement. The notice will remain open until 3/16/2026 to allow for contractors who have expressed interest to see this is no longer an active solicitation. Amendment 00006 - The closing date of this requirement has been extended to 3/16/2026. Additional documents will be uploaded under Amendment - 00006. This included DESCOPED SPECIFICATIONS AND DRAWINGS. RFI responses are uploaded here. . It is the contractor's responsivility to monitor this announcement for changes/uploaded documents. Amendment 0005 - The closing date of this requirement has been extended to 1/30/2026. See Attached Amendment 0005. Amendment 00004 - The closing date of this requirement has been extended to 11/6/2025. See Attached Amendment 00004. Amendment 00003 - The closing date for this requirement has been extended to 10/2/2025. See Attached Amendment 00003. Remember, all Amendments shall be signed and returned with your proposal or your proposal will be considered non-responsive. Amendment 00002 - Extends the close date to 7/16/2025. Amendment 00001 - Corrects the response date listed on the SF 1442, Block 13. Change the response dated from 5/23/2025 to 6/30/2025. The United States Department of Agriculture (USDA), Agricultural Research Service (ARS), Pacific West Area Office has a construction requirement for repair of the water well to include drilling a new shaft at RSPERC 19 Office Loop Duboise ID 83423. The Contractor shall provide all labor, equipment, materials, supplies, transportation and supervision performing all required work in accordance with the plans and specifications for this requirement This is the only official location where these documents can be obtained and where updates are posted. This requirement is being solicited on an UNRESTRICTED basis. Potential Offerors are responsible for monitoring this site for release of any amendments. No hard copy solicitation materials are available. No paper copies of the solicitation will be mailed, and telephone requests will not be honored. MAGNITUDE OF CONSTRUCTION PROJECT - Between $1,000,000.00 and $5,000.000.00 A single organized site visit is completed on Wednesday, 28 May, 2025 at TIME 11:00a.m. Mountain Time. No Questions will be entertained at the site visit. See below. Please ensure to sign on-site sign-in sheet All questions pertaining to this solicitation, including questions that arise during the site visit, must be submitted to theodore.blume@usda.gov by 10:00 a.m. Mountain Daylight Time, Thursday, 12 June 2025 via the Attachment VI - RFI form. Bid Bond Guarantees are also required when the proposal is above $150K. Proposals are to receive no later than 5:00 p.m. Mountain Time, Monday, 30 June 2025. Proposal must be in writing following Section L guidelines and emailed to: theodore.blume@usda.gov PROPOSAL MUST BE ANNOTATED AS SUCH AND REFERENCE THE SOLICITATION NUMBER. 12905B25R0002. Late proposals submitted after this deadline may be considered only if it is in the government s best interest and if it will not unduly delay award. Note: Performance and Payment bonds will be required after award should they meet the threshold per FAR 28.102. As a general reference, payment bonds are needed for all proposals above $35K and performance bonds are needed above $150K. Payment and Performance bonds are due ten (10) days after award and must be accepted by the Contracting Officer.