127EAW26R0001 - Brush Creek Work Center Construction 127EAW26R0001

127EAW26R0001 - Brush Creek Work Center Disclosure of Magnitude of the Construction Project: More than $10,000,000 Set Aside: Total Small Business Set Aside IMPORTANT NOTES: See Section L, Paragraph L.3 for the Documents to Submit with Your Proposal All Requests for Information (RFI's) shall be submitted to the Contracting Officer, Greg Cunningham, on the attached RFI form not later than 1300 hours PST, February 27th, 2026. An organized site visit will be held on Wednesday Feb 18th, 2026, 1:00 PM PST. See page attachment "1. Statement of Work" for full details. In no event shall failure to inspect the site constitute grounds for a claim after contract award. PLEASE RSVP TO THE SITE VISIT BY EMAILING: GREGORY.CUNNINGHAM@USDA.GOV

127EAW26R0001 - Brush Creek Work Center - A00001: Site Visit Reschedule This purpose of this amendment is to cancel and reschedule the current site visit due to inclement weather, and extend RFI submission due date. Forest Serivce led site visit on 18 Feb 2026 is hereby canceled. Site visit is rescheduled for 25 Feb 2026 at 12:00 PM PST. RFI due date is hereby extended to 6 March 2026 at 1:00 PM PST. /////////////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center Disclosure of Magnitude of the Construction Project: More than $10,000,000 Set Aside: Total Small Business Set Aside IMPORTANT NOTES: See Section L, Paragraph L.3 for the Documents to Submit with Your Proposal All Requests for Information (RFI's) shall be submitted to the Contracting Officer, Greg Cunningham, on the attached RFI form not later than 1300 hours PST, February 27th, 2026. An organized site visit will be held on Wednesday Feb 18th, 2026, 1:00 PM PST. See page attachment "1. Statement of Work" for full details. In no event shall failure to inspect the site constitute grounds for a claim after contract award. PLEASE RSVP TO THE SITE VISIT BY EMAILING: GREGORY.CUNNINGHAM@USDA.GOV

127EAW26R0001 - Brush Creek Work Center - A00002: Site Visit Roster The purpose of this amendment is to post the sign in sheet from the Forest Service led site visit held on 25 February 2026. /////////////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center - A00001: Site Visit Reschedule This purpose of this amendment is to cancel and reschedule the current site visit due to inclement weather, and extend RFI submission due date. Forest Serivce led site visit on 18 Feb 2026 is hereby canceled. Site visit is rescheduled for 25 Feb 2026 at 12:00 PM PST. RFI due date is hereby extended to 6 March 2026 at 1:00 PM PST. /////////////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center Disclosure of Magnitude of the Construction Project: More than $10,000,000 Set Aside: Total Small Business Set Aside IMPORTANT NOTES: See Section L, Paragraph L.3 for the Documents to Submit with Your Proposal All Requests for Information (RFI's) shall be submitted to the Contracting Officer, Greg Cunningham, on the attached RFI form not later than 1300 hours PST, February 27th, 2026. An organized site visit will be held on Wednesday Feb 18th, 2026, 1:00 PM PST. See page attachment "1. Statement of Work" for full details. In no event shall failure to inspect the site constitute grounds for a claim after contract award. PLEASE RSVP TO THE SITE VISIT BY EMAILING: GREGORY.CUNNINGHAM@USDA.GOV

127EAW26R0001 - Brush Creek Work Center - A00003: Time Extension and RFI Responses The purpose of this amendment is to extend the proposal due date, post RFI responses, and other applicable documentation. /////////////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center - A00002: Site Visit Roster The purpose of this amendment is to post the sign in sheet from the Forest Service led site visit held on 25 February 2026. /////////////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center - A00001: Site Visit Reschedule This purpose of this amendment is to cancel and reschedule the current site visit due to inclement weather, and extend RFI submission due date. Forest Serivce led site visit on 18 Feb 2026 is hereby canceled. Site visit is rescheduled for 25 Feb 2026 at 12:00 PM PST. RFI due date is hereby extended to 6 March 2026 at 1:00 PM PST. /////////////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center Disclosure of Magnitude of the Construction Project: More than $10,000,000 Set Aside: Total Small Business Set Aside IMPORTANT NOTES: See Section L, Paragraph L.3 for the Documents to Submit with Your Proposal All Requests for Information (RFI's) shall be submitted to the Contracting Officer, Greg Cunningham, on the attached RFI form not later than 1300 hours PST, February 27th, 2026. An organized site visit will be held on Wednesday Feb 18th, 2026, 1:00 PM PST. See page attachment "1. Statement of Work" for full details. In no event shall failure to inspect the site constitute grounds for a claim after contract award. PLEASE RSVP TO THE SITE VISIT BY EMAILING: GREGORY.CUNNINGHAM@USDA.GOV

127EAW26R0001 - Brush Creek Work Center - A00004: Time Extension and RFI Responses The purpose of this amendment is to extend the proposal due date, post RFI responses, and other applicable documentation. /////////////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center - A00003: Time Extension and RFI Responses The purpose of this amendment is to extend the proposal due date, post RFI responses, and other applicable documentation. /////////////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center - A00002: Site Visit Roster The purpose of this amendment is to post the sign in sheet from the Forest Service led site visit held on 25 February 2026. /////////////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center - A00001: Site Visit Reschedule This purpose of this amendment is to cancel and reschedule the current site visit due to inclement weather, and extend RFI submission due date. Forest Serivce led site visit on 18 Feb 2026 is hereby canceled. Site visit is rescheduled for 25 Feb 2026 at 12:00 PM PST. RFI due date is hereby extended to 6 March 2026 at 1:00 PM PST. /////////////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center Disclosure of Magnitude of the Construction Project: More than $10,000,000 Set Aside: Total Small Business Set Aside IMPORTANT NOTES: See Section L, Paragraph L.3 for the Documents to Submit with Your Proposal All Requests for Information (RFI's) shall be submitted to the Contracting Officer, Greg Cunningham, on the attached RFI form not later than 1300 hours PST, February 27th, 2026. An organized site visit will be held on Wednesday Feb 18th, 2026, 1:00 PM PST. See page attachment "1. Statement of Work" for full details. In no event shall failure to inspect the site constitute grounds for a claim after contract award. PLEASE RSVP TO THE SITE VISIT BY EMAILING: GREGORY.CUNNINGHAM@USDA.GOV

127EAW26R0001 - Brush Creek Work Center - A00005: RFI Responses 3 & SOI The purpose of this amendment is to post RFI responses, and other applicable documentation. /////////////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center - A00004: Time Extension and RFI Responses The purpose of this amendment is to extend the proposal due date, post RFI responses, and other applicable documentation. /////////////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center - A00003: Time Extension and RFI Responses The purpose of this amendment is to extend the proposal due date, post RFI responses, and other applicable documentation. /////////////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center - A00002: Site Visit Roster The purpose of this amendment is to post the sign in sheet from the Forest Service led site visit held on 25 February 2026. /////////////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center - A00001: Site Visit Reschedule This purpose of this amendment is to cancel and reschedule the current site visit due to inclement weather, and extend RFI submission due date. Forest Serivce led site visit on 18 Feb 2026 is hereby canceled. Site visit is rescheduled for 25 Feb 2026 at 12:00 PM PST. RFI due date is hereby extended to 6 March 2026 at 1:00 PM PST. /////////////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center Disclosure of Magnitude of the Construction Project: More than $10,000,000 Set Aside: Total Small Business Set Aside IMPORTANT NOTES: See Section L, Paragraph L.3 for the Documents to Submit with Your Proposal All Requests for Information (RFI's) shall be submitted to the Contracting Officer, Greg Cunningham, on the attached RFI form not later than 1300 hours PST, February 27th, 2026. An organized site visit will be held on Wednesday Feb 18th, 2026, 1:00 PM PST. See page attachment "1. Statement of Work" for full details. In no event shall failure to inspect the site constitute grounds for a claim after contract award. PLEASE RSVP TO THE SITE VISIT BY EMAILING: GREGORY.CUNNINGHAM@USDA.GOV

127EAW26R0001 - Brush Creek Work Center - A00006: Proposal Due Date The purpose of this amendment is to confirm proposal due date / time. Amendment A00005 erroneously had block 11 "is extended" checked when the proposal due date was not extended. Proposal due date and time remains April 2nd, 2026 at 1:00 PM Pacific Time. //////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center - A00005: RFI Responses 3 & SOI The purpose of this amendment is to post RFI responses, and other applicable documentation. //////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center - A00004: Time Extension and RFI Responses The purpose of this amendment is to extend the proposal due date, post RFI responses, and other applicable documentation. //////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center - A00003: Time Extension and RFI Responses The purpose of this amendment is to extend the proposal due date, post RFI responses, and other applicable documentation. //////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center - A00002: Site Visit Roster The purpose of this amendment is to post the sign in sheet from the Forest Service led site visit held on 25 February 2026. //////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center - A00001: Site Visit Reschedule This purpose of this amendment is to cancel and reschedule the current site visit due to inclement weather, and extend RFI submission due date. Forest Serivce led site visit on 18 Feb 2026 is hereby canceled. Site visit is rescheduled for 25 Feb 2026 at 12:00 PM PST. RFI due date is hereby extended to 6 March 2026 at 1:00 PM PST. //////////////////////////////////////////////////////////////////////////////////////////////// 127EAW26R0001 - Brush Creek Work Center Disclosure of Magnitude of the Construction Project: More than $10,000,000 Set Aside: Total Small Business Set Aside IMPORTANT NOTES: See Section L, Paragraph L.3 for the Documents to Submit with Your Proposal All Requests for Information (RFI's) shall be submitted to the Contracting Officer, Greg Cunningham, on the attached RFI form not later than 1300 hours PST, February 27th, 2026. An organized site visit will be held on Wednesday Feb 18th, 2026, 1:00 PM PST. See page attachment "1. Statement of Work" for full details. In no event shall failure to inspect the site constitute grounds for a claim after contract award. PLEASE RSVP TO THE SITE VISIT BY EMAILING: GREGORY.CUNNINGHAM@USDA.GOV